Chapter 4 - PRELITIGATION PROCEDURE

Section 910 - Prelitigation procedures
Section 911 - Builder defined
Section 912 - Builder's duties
Section 913 - Acknowledgment of receipt of notice of claim; claimant's legal representative included in communications
Section 914 - Nonadversarial procedure
Section 915 - Release of homeowner from provisions of chapter
Section 916 - Inspection of claimed unmet standards
Section 917 - Builder's offer to repair violation
Section 918 - Time period for authorization to proceed with repair; request for alternative contractors to make repair
Section 919 - Mediation of dispute
Section 920 - Release of claimant from chapter and filing of action
Section 921 - Repair by builder
Section 922 - Observing and recording repair
Section 923 - Copies of correspondence and materials relating to repair
Section 924 - Builder electing to repair some but not all unmet standards
Section 925 - Builder's failure to complete repair within time specified
Section 926 - Release or waiver in exchange for repair prohibited; action for violation of standard or for inadequate repair
Section 927 - Extension of statute of limitations
Section 928 - Mediation after repair completed
Section 929 - Cash offer and no repair
Section 930 - Time periods strictly construed; motion to stay until claimant satisfies requirement of chapter
Section 931 - Claim combining causes of action or damages not covered by part
Section 932 - Subsequently discovered claims of unmet standards
Section 933 - Admissibility of repair effort
Section 934 - Evidence of both parties' conduct during process
Section 935 - Action subsequently commenced under section 6000
Section 936 - Persons subject to chapter other builders; common law and contractual defenses; joint and several liability;
Section 937 - Compliance with section 411.35
Section 938 - Effective date of title