Miss. Code. tit. 27, pt. 100, ch. 8, APPENDICES, app 27-100-8-C
Note: Words appearing in brackets "[ ]" may be substituted for the appropriate state agency reference.
APPLICABLE LAW
The contract shall be governed by and construed in accordance with the laws of the State of Mississippi, excluding its conflicts of laws, provisions, and any litigation with respect thereto shall be brought in the courts of the State. Contractor shall comply with applicable federal, state, and local laws and regulations.
(The following clause, or one substantially similar, shall be required in multi-term contractual agreements only.)
AVAILABILITY OF FUNDS
It is expressly understood and agreed that the obligation of the [State] to proceed under this agreement is conditioned upon the appropriation of funds by the Mississippi State Legislature and the receipt of state and/or federal funds. If the funds anticipated for the continuing fulfillment of the agreement are, at any time, not forthcoming or insufficient, either through the failure of the federal government to provide funds or of the State of Mississippi to appropriate funds or the discontinuance or material alteration of the program under which funds were provided or if funds are not otherwise available to the [State], the [State] shall have the right upon ten (10) working days written notice to Contractor, to terminate this agreement without damage, penalty, cost or expenses to the [State] of any kind whatsoever. The effective date of termination shall be as specified in the notice of termination.
REPRESENTATION REGARDING CONTINGENT FEES
Contractor represents that it has not retained a person to solicit or secure a state contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, except as disclosed in Contractor's bid or proposal.
REPRESENTATION REGARDING GRATUITIES
The bidder, offeror, or Contractor represents that it has not violated, is not violating, and promises that it will not violate the prohibition against gratuities set forth in Section 6-204 (Gratuities) of the Mississippi Personal Service Contract Review Board Rules and Regulations.
PROCUREMENT REGULATIONS
The contract shall be governed by the applicable provisions of the Mississippi Personal Service Contract Review Board Rules and Regulations, a copy of which is available at 210 East Capitol,
Suite 800, Jackson, Mississippi 39201 for inspection, or downloadable at http://www.mspb.ms.gov.
TRADE SECRETS, COMMERCIAL AND FINANCIAL INFORMATION
It is expressly understood that Mississippi law requires that the provisions of this contract which contain the commodities purchased or the personal or professional services provided, the price to be paid, and the term of the contract shall not be deemed to be a trade secret or confidential commercial or financial information and shall be available for examination, copying, or reproduction.
COMPLIANCE WITH LAWS
Contractor understands that the [State] is an equal opportunity employer and therefore, maintains a policy which prohibits unlawful discrimination based on race, color, creed, sex, age, national origin, physical handicap, disability, genetic information, or any other consideration made unlawful by federal, state, or local laws. All such discrimination is unlawful and Contractor agrees during the term of the agreement that Contractor will strictly adhere to this policy in its employment practices and provision of services. Contractor shall comply with, and all activities under this agreement shall be subject to, all applicable federal, State of Mississippi, and local laws and regulations, as now existing and as may be amended or modified.
(Language substantially similar to the following clause shall be inserted in all Mississippi contracts requiring PSCRB approval.)
STOP WORK ORDER
(1) Order to Stop Work: The Procurement Officer, may, by written order to Contractor at any time, and without notice to any surety, require Contractor to stop all or any part of the work called for by this contract. This order shall be for a specified period not exceeding 90 days after the order is delivered to Contractor, unless the parties agree to any further period. Any such order shall be identified specifically as a stop work order issued pursuant to this clause. Upon receipt of such an order, Contractor shall forthwith comply with its terms and take all reasonable steps to minimize the occurrence of costs allocable to the work covered by the order during the period of work stoppage. Before the stop work order expires, or within any further period to which the parties shall have agreed, the Procurement Officer shall either:
(a) cancel the stop work order; or,
(b) terminate the work covered by such order as provided in the Termination for Default clause or the Termination for Convenience clause of this contract.
(2) Cancellation or Expiration of the Order: If a stop work order issued under this clause is canceled at any time during the period specified in the order, or if the period of the order or any extension thereof expires, Contractor shall have the right to resume work. An appropriate adjustment shall be made in the delivery schedule or Contractor price, or both, and the contract shall be modified in writing accordingly, if:
(a) the stop work order results in an increase in the time required for, or in Contractor's cost properly allocable to, the performance of any part of this contract; and,
(b) Contractor asserts a claim for such an adjustment within 30 days after the end of the period of work stoppage; provided that, if the Procurement Officer decides that the facts justify such action, any such claim asserted may be received and acted upon at any time prior to final payment under this contract.
(3) Termination of Stopped Work: If a stop work order is not canceled and the work covered by such order is terminated for default or convenience, the reasonable costs resulting from the stop work order shall be allowed by adjustment or otherwise.
(4) Adjustments of Price: Any adjustment in contract price made pursuant to this clause shall be determined in accordance with the Price Adjustment clause of this contract.
E-PAYMENT
Contractor agrees to accept all payments in United States currency via the State of Mississippi's electronic payment and remittance vehicle. The agency agrees to make payment in accordance with Mississippi law on "Timely Payments for Purchases by Public Bodies," which generally provides for payment of undisputed amounts by the agency within forty-five (45) days of receipt of invoice. Mississippi Code Annotated § 31-7-305.
E-VERIFICATION
If applicable, Contractor represents and warrants that it will ensure its compliance with the Mississippi Employment Protection Act of 2008, and will register and participate in the status verification system for all newly hired employees. Mississippi Code Annotated §§ 71-11-1et seq. The term "employee" as used herein means any person that is hired to perform work within the State of Mississippi. As used herein, "status verification system" means the Illegal Immigration Reform and Immigration Responsibility Act of 1996 that is operated by the United States Department of Homeland Security, also known as the E-Verify Program, or any other successor electronic verification system replacing the E-Verify Program. Contractor agrees to maintain records of such compliance. Upon request of the State and after approval of the Social Security Administration or Department of Homeland Security when required, Contractor agrees to provide a copy of each such verification. Contractor further represents and warrants that any person assigned to perform services hereafter meets the employment eligibility requirements of all immigration laws. The breach of this agreement may subject Contractor to the following:
(1) termination of this contract for services and ineligibility for any state or public contract in Mississippi for up to three (3) years with notice of such cancellation/termination being made public;
(2) the loss of any license, permit, certification or other document granted to Contractor by an agency, department or governmental entity for the right to do business in Mississippi for up to one (1) year; or,
(3) both. In the event of such cancellation/termination, Contractor would also be liable for any additional costs incurred by the State due to Contract cancellation or loss of license or permit to do business in the State.
TRANSPARENCY
This contract, including any accompanying exhibits, attachments, and appendices, is subject to the "Mississippi Public Records Act of 1983," and its exceptions. See Mississippi Code Annotated §§ 25-61-1et seq. and Mississippi Code Annotated § 79-23-1. In addition, this contract is subject to the provisions of the Mississippi Accountability and Transparency Act of 2008. Mississippi Code Annotated §§ 27-104-151et seq. Unless exempted from disclosure due to a court-issued protective order, a copy of this executed contract is required to be posted to the Department of Finance and Administration's independent agency contract website for public access at http://www.transparency.mississippi.gov. Information identified by Contractor as trade secrets, or other proprietary information, including confidential vendor information or any other information which is required confidential by state or federal law or outside the applicable freedom of information statutes, will be redacted.
Contracts, except those for contract workers paid in SPAHRS or for Contractors exempted from this rule, must include the following language:
PAYMODE
Payments by state agencies using the State's accounting system shall be made and remittance information provided electronically as directed by the State. These payments shall be deposited into the bank account of Contractor's choice. The State may, at its sole discretion, require Contractor to electronically submit invoices and supporting documentation at any time during the term of this Agreement. Contractor understands and agrees that the State is exempt from the payment of taxes. All payments shall be in United States currency.
TERMINATION FOR CONVENIENCE
(1) Termination. The Agency Head or designee may, when the interests of the State so require, terminate this contract in whole or in part, for the convenience of the State. The Agency Head or designee shall give written notice of the termination to Contractor specifying the part of the contract terminated and when termination becomes effective.
(2) Contractor's Obligations. Contractor shall incur no further obligations in connection with the terminated work and on the date set in the notice of termination Contractor will stop work to the extent specified. Contractor shall also terminate outstanding orders and subcontracts as they relate to the terminated work. Contractor shall settle the liabilities and claims arising out of the termination of subcontracts and orders connected with the terminated work. The Agency Head or designee may direct Contractor to assign Contractor's right, title, and interest under terminated orders or subcontracts to the State. Contractor must still complete the work not terminated by the notice of termination and may incur obligations as are necessary to do so.
TERMINATION FOR DEFAULT
(1) Default. If Contractor refuses or fails to perform any of the provisions of this contract with such diligence as will ensure its completion within the time specified in this contract or any extension thereof, or otherwise fails to timely satisfy the contract provisions, or commits any other substantial breach of this contract, the Agency Head or designee may notify Contractor in writing of the delay or nonperformance and if not cured in ten (10) days or any longer time specified in writing by the Agency Head or designee, such officer may terminate Contractor's right to proceed with the contract or such part of the contract as to which there has been delay or a failure to properly perform. In the event of termination in whole or in part, the Agency Head or designee may procure similar supplies or services in a manner and upon terms deemed appropriate by the Agency Head or designee. Contractor shall continue performance of the contract to the extent it is not terminated and shall be liable for excess costs incurred in procuring similar goods or services.
(2) Contractor's Duties. Notwithstanding termination of the contract and subject to any directions from the procurement officer, Contractor shall take timely, reasonable, and necessary action to protect and preserve property in the possession of Contractor in which the State has an interest.
(3) Compensation. Payment for completed services delivered and accepted by the State shall be at the contract price. The State may withhold from amounts due Contractor such sums as the Agency Head or designee deems to be necessary to protect the State against loss because of outstanding liens or claims of former lien holders and to reimburse the State for the excess costs incurred in procuring similar goods and services.
(4) Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor has notified the Agency Head or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Agency Head or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor's progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, "Termination for Convenience," in cost-reimbursement contracts, "Termination").
(As used in this Paragraph of this clause, the term "subcontractor" means subcontractor at any tier).
(5) Erroneous Termination for Default. If, after notice of termination of Contractor's right to proceed under the provisions of this clause, it is determined for any reason that the contract was not in default under the provisions of this clause, or that the delay was excusable under the provisions of Paragraph (4) (Excuse for Nonperformance or Delayed Performance) of this clause, the rights and obligations of the parties shall, if the contract contains a clause providing for termination for convenience of the State, be the same as if the notice of termination had been issued pursuant to such clause.
(6) Additional Rights and Remedies. The rights and remedies provided in this clause are in addition to any other rights and remedies provided by law or under this contract.
TERMINATION UPON BANKRUPTCY
This contract may be terminated in whole or in part by [agency] upon written notice to Contractor, if Contractor should become the subject of bankruptcy or receivership proceedings, whether voluntary or involuntary, or upon the execution by Contractor of an assignment for the benefit of its creditors. In the event of such termination, Contractor shall be entitled to recover just and equitable compensation for satisfactory work performed under this contract, but in no case shall said compensation exceed the total contract price.
Miss. Code. tit. 27, pt. 100, ch. 8, APPENDICES, app 27-100-8-C